Terms of Service

Payment terms depend on project size:

- Small Projects (below $100): Full payment upfront or 50% down payment

- Large Projects: Milestone-based payments until completion

- Long-term Projects: Weekly hourly-based payments

Payment methods: Western Union, PayPal, Transferwise, bank transfer, GCash, Maya, Bitcoin, Ethereum, Ripple

Unclaimed and unpaid work after 7 days may be offered to other clients

All payments are final

Delivery dates may change based on circumstances, but we include buffer time for potential delays

Pricing includes not just code, but expertise and research time

Some changes, even small ones, may require significant investigation time

Projects are exclusive by default - no previews shared without permission

We implement ideas exactly as specified - additions incur extra costs

We provide recommendations for best implementation methods

Please finalize ideas before project start

All revisions after initial quote have additional costs

Without complete specifications, we use our best judgment - revisions will cost extra

Bug fixes for quoted features are free

Compatibility updates supported for 1 month

Major emulator changes requiring updates will have additional costs

No redistribution without permission

Client details and ideas remain confidential